TERMS AND CONDITIONS
TononLimitedTADoctorHomeIreland
Effective Date: 14/08/2025
1. Introduction
Welcome to Doctor Home Ireland ("Company", "we", "us", or "our"). These Terms and Conditions ("Terms") govern the provision of renovation services ("Services") by the Company to the Client ("Client", "you", or "your"). By requesting or using our Services, you agree to be bound by these Terms.
2. Scope of Work
2.1 The scope of Services to be performed will be detailed in a written quotation or contract and may include, but is not limited to: interior/exterior renovations, kitchen and bathroom remodels, flooring, painting, plumbing, and electrical work.
2.2 Any changes to the agreed scope must be confirmed in writing and may be subject to additional costs and time.
3. Quotes and Pricing
3.1 All quotes are valid for 30 days unless stated otherwise.
3.2 Prices may be adjusted if there is a change in scope, availability of materials, or unforeseen circumstances during the renovation.
3.3 A detailed invoice will be issued upon completion of the work or as per agreed milestone payments.
4. Payment Terms
4.1 A deposit of 10% is required to secure your project booking.
4.2 A 40% payment is required on the first day of work.
4.2 Progress payments may be required for larger projects and will be outlined in your agreement.
4.3 Final payment is due upon project completion.
4.4 The Company reserves the right to suspend or terminate Services if payments are not made as agreed.
5. Client Responsibilities
5.1 The Client must ensure the worksite is accessible and free of hazards.
5.2 The Client is responsible for obtaining any necessary permits unless otherwise stated in writing.
5.3 The Client agrees to provide accurate information and decisions promptly to avoid delays.
6. Delays and Force Majeure
6.1 We are not responsible for delays caused by weather, supply chain disruptions, labor shortages, government regulations, or other events beyond our control.
6.2 In such events, timelines will be adjusted accordingly, and the Client will be notified.
7. Warranties and Guarantees
7.1 We warrant that all work will be carried out in a professional manner and in accordance with industry standards.
7.2 Materials and products used may carry their own manufacturer warranties.
7.3 Warranty claims must be made in writing within 6 months of project completion.
8. Liability
8.1 Our liability is limited to the value of the Services provided.
8.2 We are not liable for indirect, incidental, or consequential damages.
8.3 The Client agrees to indemnify and hold the Company harmless from any third-party claims arising out of the use or misuse of the renovated premises.
9. Termination
9.1 Either party may terminate the agreement with written notice if the other party breaches any material term.
9.2 In the event of termination, the Client is responsible for payment for all work completed up to the date of termination, including any incurred costs or restocking fees.
10. Intellectual Property
10.1 Any designs, plans, or documentation provided by the Company remain the intellectual property of the Company unless agreed otherwise in writing.
11. Photography and Promotion
11.1 The Company reserves the right to take photographs of completed work for use in portfolios, websites, and promotional materials unless the Client opts out in writing.
12. Governing Law
12.1 These Terms shall be governed by and construed in accordance with the laws of Ireland.
12.2 Any disputes shall be resolved in the courts of Dublin, Ireland.
13. Entire Agreement
13.1 These Terms, along with any written quotes or contracts, constitute the entire agreement between the Client and the Company.
13.2 No verbal agreements or representations are binding unless confirmed in writing.
Contact Information
Tonon Limited TA Doctor Home Ireland
doctorhomeireland[at]gmail.com
www.doctorhomeireland.com